Tran. FBN No. 2017-0001343. Published May 17, 24, 31, June 7, 2017.
CITY OF SANTA BARBARA NOTICE TO CONTRACTORS BID NO. 3710A Sealed proposals for Bid No. 3710A for the BRIDGE PREVENTIVE MAINTENANCE PROGRAM-2ND CYCLE will be received in the Purchasing Office, 310 E. Ortega Street, Santa Barbara, California 93101, until 3:00 p.m., Tuesday, June 20, 2017 to be publicly opened and read at that time. Any bidder who wishes its bid proposal to be considered is responsible for making certain that its bid proposal is actually delivered to said Purchasing Office. Bids shall be addressed to the General Services Manager, Purchasing Office, 310 E. Ortega Street, Santa Barbara, California, and shall be labeled, “BRIDGE PREVENTIVE MAINTENANCE PROGRAM2ND CYCLE, Bid No. 3710A". The work includes all labor, material, supervision, plant and equipment necessary to complete the following: Deck Treatment with High Molecular Weight Methacrylate (HMWM), Epoxy Crack Injection, Concrete Spall Repair, Bridge Rail Repair and Painting, Wooden Deck Replacement, and other maintenance at seven bridges in the City of Santa Barbara per plans and specs. The Engineer’s estimate is $245,000. Each bidder must have a Class A General Engineering Contractor license to complete this work in accordance with the California Business and Professions Code. The plans and specifications for this Project are available electronically at SantaBarbaraCA.gov/ebidboard. Plan and specification sets can be obtained from CyberCopy (located at 504 N Milpas St, cross street Haley) by contacting Alex Gaytan, CyberCopy Shop Manager, at (805) 884-6155. The City’s contact for this project is Max Kashanian, Project Engineer, 805-564-5450. In order to be placed on the plan holder’s list, the Contractor can register as a document holder for this Project on Ebidboard. Project Addendum notifications will be issued through Ebidboard.com. Although Ebidboard will fax and/or email all notifications once they are provided contact information, bidders are still responsible for obtaining all addenda from the Ebidboard website or the City’s website at: SantaBarbaraCA.gov/ebidboard. Bidders are hereby notified that pursuant to provisions of Section 1770, et seq., of the Labor Code of the State of California, the Contractor shall pay its employees the general prevailing rate of wages as determined by the Director of the Department of Industrial Relations. The Federal minimum wage rates for this project as predetermined by the United States Secretary of Labor are set forth in Appendix B of the specifications and are available from California Deparment of Transportation Internet web site at http://www.dot.ca.gov/hq/esc/oe/federal-wages/. Addenda to modify the Federal minimum wage rates, if necessary, will be issued to holders of these specifications. If there is a difference between the minimum wage rates predetermined by the Secretary of Labor and the general prevailing wage rates determined by the Director of the California Department of Industrial Relates for similar classifications of labor, the Contractor and Subcontractors must pay not less than the higher wage rate. The City of Santa Barbara will not accept lower State wage rates not specifically included in the Federal minimum wage determinations. This includes “helper” (or other classifications based on hours of experience) or any other classification not appearing in the Federal wage determinations. Where Federal wage determinations do not contain the State wage determinations otherwise available for use by the Contractor and Subcontractors, the Contractor and Subcontractors must pay not less than the Federal minimum wage rate which most closely approximates the duties of the employees in question. In addition, the Contractor shall be responsible for compliance with the requirements of Section 1777.5 of the California Labor Code relating to apprentice public works contracts. Per California Civil Code Section 9550, a payment bond in the amount of 100% of the bid total will be required from the successful bidder for bids exceeding $25,000. The bond must be provided within 10 calendar days from notice of award and prior to the performance of any work. The proposal shall be accompanied by a proposal guaranty bond in the sum of at least 10% of the total amount of the proposal, or alternatively by a certified or cashier’s check payable to the Owner in the sum of at least 10% of the total amount of the proposal. A separate performance bond in the amount of 100% of the bid total will be required from the successful bidder. The bond must be provided within 10 calendar days from the notice to award and prior to the performance of any work. Effective March 1, 2015, Senate Bill 854 requires the City to only use contractors and subcontractors on public projects that have been registered with the State of California Department of Industrial Relations. The City of Santa Barbara hereby notifies all bidders that it will affirmatively insure that in any contract entered into pursuant to this advertisement, minority business enterprises will be afforded full opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, creed, color, national origin, ancestry, sexual orientation, political affiliations or beliefs, sex, age, physical disability, medical condition, marital status or pregnancy as set forth hereunder. Bidders are advised that, as required by federal law, the State has established a statewide overall Disadvantaged Business Enterprise (DBE) goal. This Agency federal-aid contract is considered to be part of the statewide overall DBE goal. The Agency is required to report to Caltrans on DBE participation for all federal-aid contracts each year so that attainment efforts may be evaluated. This federalaid contract has a goal of 5 percent DBE participation. This project is subject to the “Buy America” provisions of the Surface Transportation Assistance Act of 1982 as amended by the Intermodal Surface Transportation Efficiency Act of 19991. The U.S. Department of Transportation (DOT) provides a toll-free hotline to report bid rigging activities. Use the hotline to report bid rigging, bidder collusion, and other fraudulent activities. The hotline number is (800) 424-9071. The service is available 24 hours 7 days a week and is confidential and anonymous.. The hotline is part of the DOT's effort to identify and investigate highway construction contract fraud and abuse and is operated under the direction of the DOT Inspector General.
GENERAL SERVICES MANAGER CITY OF SANTA BARBARA
William Hornung, C.P.M. PUBLISHED: May 31, June 7 and 14, 2017 Montecito Journal
the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL) by Melissa Mercer. FBN No. 2017-0001505. Published May 24, 31, June 7, 14, 2017.
copy of the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL) by Noe Solis. FBN No. 2017-0001155. Published May 17, 24, 31, June 7, 2017.
FICTITIOUS BUSINESS NAME STATEMENT: The following person(s) is/are doing business as: Z & Z Consulting, 856 Ferrelo Place, Santa Barbara, CA 93103. Yuan Linda Zhang, 856 Ferrelo Place, Santa Barbara, CA 93103. Nan Zhou, 856 Ferrelo Place, Santa Barbara, CA 93103. This statement was filed with the County Clerk of Santa Barbara County on April 18, 2017. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct
FICTITIOUS BUSINESS NAME STATEMENT: The following person(s) is/are doing business as: Rite Aid #05835, 345 Town Center West, Santa Maria, CA 93458-5076. Thrifty Payless, INC, 30 Hunter Lane, Camp Hill, PA 17011. This statement was filed with the County Clerk of Santa Barbara County on May 3, 2017. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland,
1 – 8 June 2017
County Clerk (SEAL) by Connie Tran. FBN No. 2017-0001347. Published May 17, 24, 31, June 7, 2017.
Clerk (SEAL) by Connie Tran. FBN No. 2017-0001341. Published May 17, 24, 31, June 7, 2017.
FICTITIOUS BUSINESS NAME STATEMENT: The following person(s) is/are doing business as: Rite Aid #05776, 801 Linden Avenue, Carpinteria, CA 93013-2042. Thrifty Payless, INC, 30 Hunter Lane, Camp Hill, PA 17011. This statement was filed with the County Clerk of Santa Barbara County on May 3, 2017. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland, County
FICTITIOUS BUSINESS NAME STATEMENT: The following person(s) is/are doing business as: Rite Aid #05788, 35 South Milpas Street, Santa Barbara, CA 93103-3305. Thrifty Payless, INC, 30 Hunter Lane, Camp Hill, PA 17011. This statement was filed with the County Clerk of Santa Barbara County on May 3, 2017. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL) by Connie
In early June, the world of leaf and blade and flowers explodes. – John Steinbeck
FICTITIOUS BUSINESS NAME STATEMENT: The following person(s) is/are doing business as: Rite Aid #06185, 616 Alamo Pintado Road, Solvang, CA 93463-2202. Thrifty Payless, INC, 30 Hunter Lane, Camp Hill, PA 17011. This statement was filed with the County Clerk of Santa Barbara County on May 3, 2017. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL) by Connie Tran. FBN No. 2017-0001353. Published May 17, 24, 31, June 7, 2017. FICTITIOUS BUSINESS NAME STATEMENT: The following person(s) is/are doing business as: Rite Aid #05790, 1976 Cliff Drive, Santa Barbara, CA 93109-1504. Thrifty Payless, INC, 30 Hunter Lane, Camp Hill, PA 17011. This statement was filed with the County Clerk of Santa Barbara County on May 3, 2017. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL) by Connie Tran. FBN No. 2017-0001344. Published May 17, 24, 31, June 7, 2017. FICTITIOUS BUSINESS NAME STATEMENT: The following person(s) is/are doing business as: Rite Aid #05791, 199 North Fairview Avenue, Goleta, CA 93117-2304. Thrifty Payless, INC, 30 Hunter Lane, Camp Hill, PA 17011. This statement was filed with the County Clerk of Santa Barbara County on May 3, 2017. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL) by Connie Tran. FBN No. 2017-0001346. Published May 17, 24, 31, June 7, 2017. FICTITIOUS BUSINESS NAME STATEMENT: The following person(s) is/are doing business as: Rite Aid #05836, 2405 South Broadway, Santa Maria, CA 93454-7817. Thrifty Payless, INC, 30 Hunter Lane, Camp Hill, PA 17011. This statement was filed with the County Clerk of Santa Barbara County on May 3, 2017. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL) by Connie Tran. FBN No. 2017-0001352. Published May 17, 24, 31, June 7, 2017. FICTITIOUS BUSINESS NAME STATEMENT: The following person(s) is/are doing business as: Impact Family Office, 1224 Coast Village Circle, Suite 11, Santa Barbara, CA 93108. Impact First Financial, LLC, 1224 Coast Village Circle, Suite 11, Santa Barbara, CA 93108. This statement was filed with the County Clerk of Santa Barbara County on May 10, 2017. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL) by Connie Tran. FBN No. 2017-0001425. Published May 17, 24, 31, June 7, 2017. FICTITIOUS BUSINESS NAME STATEMENT: The following person(s) is/are doing business as: Musicology Santa Barbara, 1070 Fairway Road, Santa Barbara, CA 93108. Allison Wanberg, 27602 Silver Creek Drive, San Juan Capistrano, CA 92675. This statement was filed with the County Clerk of Santa Barbara County on May 11,
2017. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL) by Tara Jayasinghe. FBN No. 2017-0001437. Published May 17, 24, 31, June 7, 2017. FICTITIOUS BUSINESS NAME STATEMENT: The following person(s) is/are doing business as: Alice Brophy Fashion Stylist, 1410 Chino Street, Santa Barbara, CA, 93101. Alice Richardson, 1410 Chino Street, Santa Barbara, CA, 93101. This statement was filed with the County Clerk of Santa Barbara County on May 1, 2017. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL) by Jessica Sheaff. FBN No. 2017-0001317. Published May 17, 24, 31, June 7, 2017. FICTITIOUS BUSINESS NAME STATEMENT OF ABANDONMENT: The following person(s) has (have) abandoned the use of the Fictitious Business Name(s): Next Chapter SB Properties, 1482 East Valley Road #300, åSanta Barbara, CA 93108. Robert Pavloff, 1482 East Valley Road #300, Santa Barbara, CA 93108; Gregory Pavloff, 1482 East Valley Road #300, Santa Barbara, CA 93108. This statement was originally filed with the County Clerk of Santa Barbara County on February 29, 2016. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL) by Connie Tran, filed May 1, 2017. Original FBN No. 2016-0000594. Published May 17, 24, 31, June 7, 2017. ORDER TO SHOW CAUSE FOR CHANGE OF NAME: CASE No. 17CV01875. To all interested parties: Petitioners Domingo Ramirez and Zoraya Ivonne Pamela Elias filed a petition with Superior Court of California, County of Santa Barbara, for a decree changing name of child from Ronnie D. Ramirez to Ronnie Ramirez. The Court orders that all persons interested in this matter appear before this court at the hearing indicated below to show cause, if any, why the petition for change of name should not be granted. Any person objecting to the name changes described above must file a written objection that includes the reasons for the objection at least two court days before the matter is scheduled to be heard and must appear at the hearing to show cause why the petition should not be granted. If no written objection is timely filed, the court may grant the petition without a hearing. Filed May 10, 2017 by Terri Chavez, Deputy Clerk. Hearing date: June 21, 2017 at 9:30 am in Dept. 6, 1100 Anacapa Street, Santa Barbara, CA 93101. Published 5/17, 5/24, 5/31, 6/7 ORDER FOR PUBLICATION OF SECOND AMENDED PLANTIFF’S CLAIM AND ORDER TO GO TO SMALL CLAIMS COURT: CASE No. 16CV05629. Notice to Defendant David Willows: You have been sued by Plaintiff: Manual Teoyotl Vargas (DBA 805-Lath & Plastering). You and the plaintiff must go to court on July 6, 2017, at 1:30 pm in Department 3 at the Santa Barbara Superior Court, 1100 Anacapa Street, Santa Barbara, CA 93101. A letter or phone call will not protect you. If you lose, the court can order that your wages, money, or property be taken to pay this claim. Bring witnesses, receipts, and any evidence you need to prove your case. The plaintiff claims the defendant owes $7,380 for work performed at 6693 Del Playa Drive in Goleta, CA. Filed May 18, 2017, by Sarah Sisto, Deputy Clerk. Published May 24, 31, June 7, 14, 2017.
MONTECITO JOURNAL
39